Download This Version in Microsoft Word format
Indicates Matter Stricken
Indicates New Matter
Indicates Matter Stricken
Indicates New Matter
AMENDED
March 8, 2005
H. 3008
Introduced by Reps. Cato, Bales, Clark, Barfield, Huggins, Frye, Sandifer, E.H. Pitts, Taylor, Anthony, Bailey, Battle, Bingham, Ceips, Chalk, Chellis, Clemmons, Cooper, Dantzler, Davenport, Duncan, Edge, Hamilton, Hardwick, Harrell, Hinson, Kirsh, Leach, Limehouse, Littlejohn, Loftis, McCraw, Norman, Owens, Perry, Pinson, Rice, Simrill, Skelton, D.C. Smith, G.R. Smith, J.R. Smith, Stewart, Thompson, Toole, Townsend, Tripp, Umphlett, Vaughn, Vick, Viers, Walker, White, Whitmire, Wilkins, Witherspoon, Coates, Brady, Ballentine, Ott, Mahaffey, Haley, Hagood, Bowers and Young
S. Printed 3/8/05--S.
Read the first time February 17, 2005.
TO AMEND THE CODE OF LAWS OF SOUTH CAROLINA, 1976, BY ADDING CHAPTER 32 TO TITLE 15, SO AS TO ENACT THE "SOUTH CAROLINA ECONOMIC DEVELOPMENT, CITIZENS, AND SMALL BUSINESS PROTECTION ACT OF 2005", PROVIDING FOR DEFINITIONS OF THE TERMS "DAMAGES", "FAULT", AND "PERSON", SEVERAL LIABILITY IN AN ACTION FOR PERSONAL INJURY, PROPERTY DAMAGE, OR WRONGFUL DEATH, A PROCEDURE FOR ASSESSING PERCENTAGES OF FAULT, JOINT LIABILITY ON ALL WHO CONSCIOUSLY AND DELIBERATELY PURSUE A COMMON PLAN TO COMMIT A TORTIOUS ACT, PLACEMENT OF THE BURDEN OF PROVING FAULT ON THE PERSON SEEKING TO ESTABLISH FAULT, AND AN EXCEPTION TO THE PROVISIONS OF THE CHAPTER; TO AMEND SECTION 15-3-640, RELATING TO AN ACTION BASED UPON A DEFECTIVE OR UNSAFE IMPROVEMENT TO REAL PROPERTY, SO AS TO DECREASE THE TIME AN ACTION MAY BE BROUGHT FROM THIRTEEN TO SIX YEARS AFTER THE SUBSTANTIAL COMPLETION OF THE IMPROVEMENT; TO AMEND SECTION 15-7-30, RELATING TO ACTIONS THAT MUST BE TRIED WHERE THE DEFENDANT RESIDES, SO AS TO DEFINE KEY TERMS AND TO PROVIDE FACTORS FOR THE COURT TO CONSIDER WHEN DETERMINING THE PRINCIPAL PLACE OF BUSINESS; TO AMEND SECTION 15-36-10, AS AMENDED, RELATING TO LIABILITY FOR ATTORNEY'S FEES AND COSTS OF FRIVOLOUS LAWSUITS, SO AS TO REPLACE THE EXISTING PROVISIONS WITH PROVISIONS REQUIRING THE SIGNATURE OF AN ATTORNEY OR PARTY ON ALL PLEADINGS AND OTHER DOCUMENTS FILED IN A CIVIL OR ADMINISTRATIVE ACTION, TO PROVIDE A PROCEDURE FOR ADMINISTERING SANCTIONS FOR A VIOLATION, AND TO PROVIDE FOR THE REPORTING OF AN ATTORNEY TO THE COMMISSION ON LAWYER CONDUCT; TO AMEND SECTION 36-2-803, RELATING TO PERSONAL JURISDICTION BASED UPON CONDUCT, SO AS TO ALLOW THE COURT TO CHANGE THE PLACE OF TRIAL WHEN THE CONVENIENCE OF WITNESSES AND THE ENDS OF JUSTICE WOULD BE PROMOTED BY THE CHANGE; TO REPEAL SECTIONS 15-36-20, 15-36-30, 15-36-40, AND 15-36-50 ALL RELATING TO FRIVOLOUS LAWSUITS, AND SECTION 58-23-90 RELATING TO VENUE IN ACTIONS AGAINST LICENSED MOTOR CARRIERS.
Amend Title To Conform
Be it enacted by the General Assembly of the State of South Carolina:
SECTION 1. The General Assembly finds that the sections presented in this act constitute one subject as required by Article III, Section 17 of the South Carolina Constitution, in particular finding that each change and each topic relates directly to or in conjunction with other sections to the subject of tort and other civil action reform as clearly enumerated in the title.
The General Assembly further finds that a common purpose or relationship exists among the sections, representing a potential plurality but not disunity of topics, notwithstanding that reasonable minds might differ in identifying more than one topic contained in the act.
SECTION 2. Section 15-3-640 of the 1976 Code is amended to read:
"Section 15-3-640. No actions to recover damages based upon or arising out of the defective or unsafe condition of an improvement to real property may be brought more than thirteen eight years after substantial completion of such an the improvement. For purposes of this section, an action based upon or arising out of the defective or unsafe condition of an improvement to real property includes:
(1) an action to recover damages for breach of a contract to construct or repair an improvement to real property;
(2) an action to recover damages for the negligent construction or repair of an improvement to real property;
(3) an action to recover damages for personal injury, death, or damage to property;
(4) an action to recover damages for economic or monetary loss;
(5) an action in contract or in tort or otherwise;
(6) an action for contribution or indemnification for damages sustained on account of an action described in this subdivision section;
(7) an action against a surety or guarantor of a defendant described in this section;
(8) an action brought against any current or prior owner of the real property or improvement, or against any other person having a current or prior interest in the real property or improvement;
(9) an action against owners or manufacturers of components, or against any person furnishing materials, or against any person who develops real property, or who performs or furnishes the design, plans, specifications, surveying, planning, supervision, testing, or observation of construction, or construction of an improvement to real property, or a repair to an improvement to real property.
This section describes an outside limitation of thirteen eight years after the substantial completion of the improvement, within which normal statutes of limitations continue to run.
Any A building permit for the construction of an improvement to real property shall must contain in bold type notice to the owner or possessor of the property of his rights under this section to contract for a guarantee of the structure being free from defective or unsafe conditions beyond thirteen eight years after substantial completion of the improvement. The Department of Consumer Affairs shall publish in conspicuous places the right of any an owner or possessor to contract for such extended liability under this section. Nothing in this section shall prohibit any prohibits a person from entering into any a contractual agreement prior to the substantial completion of the improvement which extends any guarantee of a structure or component being free from defective or unsafe conditions beyond thirteen eight years after substantial completion of the improvement or component.
For any improvement to real property, a certificate of occupancy issued by a county or municipality, in the case of new construction or completion of a final inspection by the responsible building official in the case of improvements to existing improvements, shall constitute proof of substantial completion of the improvement under the provisions of Section 15-3-630, unless the contractor and owner, by written agreement, establish a different date of substantial completion."
SECTION 3. Section 15-7-30 of the 1976 Code is amended to read:
"Section 15-7-30. (A) As used in this section:
(1) 'Domestic corporation' means a 'domestic corporation' as defined in Section 33-1-400.
(2) 'Domestic limited partnership' means a 'domestic limited partnership' as defined in Section 33-42-20.
(3) 'Domestic limited liability company' means a 'domestic limited liability partnership' as defined in Section 33-41-1110 with its principal place of business within this State.
(4) 'Domestic limited liability partnership' means a 'domestic limited liability partnership' as defined in Section 33-41-1110 with its principal place of business within this State.
(5) 'Foreign corporation' means a 'foreign corporation' as defined in Section 33-1-400.
(6) 'Foreign limited partnership' means a 'foreign limited partnership' as defined in Section 33-42-20.
(7) 'Foreign limited liability company' means a 'foreign limited liability partnership' as defined in Section 33-41-1150 with its principal place of business outside this State.
(8) 'Foreign limited liability partnership' means a 'foreign limited liability partnership' as defined in Section 33-41-1150 with its principal place of business outside this State.
(9) 'Nonresident individual' means a person who is not domiciled in this State.
(10) 'Principal place of business' means:
(a) the corporation's home office location within the State from which the corporation's officers direct, control, or coordinate its activities;
(b) the location of the corporation's manufacturing, sales, or purchasing facility within the State if the corporation does not have a home office within the State; or
(c) the location at which the majority of corporate activity takes place if the corporation has multiple offices, centers of manufacturing, sales, or purchasing located within the State if the corporation does not have a home office within the State and has more than one manufacturing, sales or purchasing facility within the State. The following factors may be considered when determining the location at which the majority of corporate activity takes place:
(i) the number of employees located in any one county;
(ii) the authority of the employees located in any one county; or
(iii) the tangible corporate assets that exist in any one county.
(11) 'Resident individual' means a person who is domiciled in this State.
(B) In all other cases not provided for in Sections 15-7-10, 15-7-20, or 15-78-100, the action shall must be tried in the county where it properly may be brought and tried against the defendant according to the provisions of this section in which the defendant resides at the time of the commencement of the action. If there be is more than one defendant then the action may be tried in any county where the action properly may be maintained against one of the defendants pursuant to this section. in which one or more of the defendants to such action resides at the time of the commencement of the action. If none of the parties shall reside in the State the action may be tried in any county which the plaintiff shall designate in his complaint. This section is subject however to the power of the court in the county where the action properly may be maintained according to this section to change the place of trial as provided in Section 15-7-100 or as otherwise in certain cases as provided by law.
(C) A civil action tried pursuant to this section against a resident individual defendant must be brought and tried in the county in which the:
(1) defendant resides at the time the cause of action arose; or
(2) most substantial part of the alleged act or omission giving rise to the cause of action occurred.
(D) A civil action tried pursuant to this section against a nonresident individual defendant must be brought and tried in the county in which the:
(1) most substantial part of the alleged act or omission giving rise to the cause of action occurred; or
(2) plaintiff resides at the time the cause of action arose, or if the plaintiff is a domestic corporation, domestic limited partnership, domestic limited liability company, domestic limited liability partnership, foreign corporation, foreign limited partnership, foreign limited liability company, or foreign limited liability partnership, at its principal place of business at the time the cause of action arose.
(E) A civil action tried pursuant to this section against a domestic corporation, domestic limited partnership, domestic limited liability company, or domestic limited liability partnership, must be brought and tried in the county in which the:
(1) corporation, limited partnership, limited liability company, or limited liability partnership has its principal place of business at the time the cause of action arose; or
(2) most substantial part of the alleged act or omission giving rise to the cause of action occurred.
(F) A civil action tried pursuant to this section against a foreign corporation required to possess a certificate of authority under the provisions of Section 33-15-101 et seq., a foreign limited partnership required to possess a certificate of authority under the provisions of Section 33-15-101 et seq., foreign limited liability company required to possess a certificate of authority under the provisions of Section 33-15-101 et seq., or foreign limited liability partnership required to possess a certificate of authority under the provisions of Section 33-15-101 et seq. must be brought and tried in the county in which the:
(1) most substantial part of the alleged act or omission giving rise to the cause of action occurred; or
(2) foreign corporation, foreign limited partnership, foreign limited liability company, or foreign limited liability partnership has its principal place of business at the time the cause of action arose.
(G) A civil action tried pursuant to this section against a foreign corporation not required to possess a certificate of authority under the provisions of Section 33-15-101 et seq., foreign limited partnership not required to possess a certificate of authority under the provisions of Section 33-15-101 et seq., foreign limited liability company not required to possess a certificate of authority under the provisions of Section 33-15-101 et seq., or foreign limited liability partnership not required to possess a certificate of authority under the provisions of Section 33-15-101 et seq. must be brought and tried in the county in which the:
(1) most substantial part of the alleged act or omission giving rise to the cause of action occurred;
(2) plaintiff resides at the time the cause of action arose, or if the plaintiff is a domestic corporation, domestic limited partnership, domestic limited liability company, domestic limited liability partnership, foreign corporation, foreign limited partnership, foreign limited liability company, or foreign limited liability partnership, at its principal place of business at the time the cause of action arose; or
(3) foreign corporation, foreign limited partnership, foreign limited liability company, or foreign limited liability partnership has its principal place of business at the time the cause of action arose.
(H) Owning property and transacting business in a county is insufficient in and of itself to establish the principal place of business for a corporation for purposes of this section."
SECTION 5. Section 15-36-10 of the 1976 Code is amended to read:
"Section 15-36-10. (A)(1) Any person who takes part in the procurement, initiation, continuation, or defense of any civil proceeding is subject to being assessed for payment of all or a portion of the attorney's fees and court costs of the other party if:
(1) he does so primarily for a purpose other than that of securing the proper discovery, joinder of parties, or adjudication of the claim upon which the proceedings are based; and
(2) the proceedings have terminated in favor of the person seeking an assessment of the fees and costs.
As used in this chapter, `person' is defined to mean any individual, corporation, company, association, firm, partnership, society, joint stock company, and any other entity, including any governmental entity or unincorporated association of persons. A pleading filed in a civil or administrative action on behalf of a party who is represented by an attorney must be signed by at least one attorney of record who is an active member of the South Carolina Bar or who is admitted to practice in the courts of this State and must include the address and telephone number of the attorney signing the document.
(2) A document filed in a civil or administrative action by a party who is not represented by an attorney must be signed by the party and must include the address and telephone number of the party.
(3) The signature of an attorney or a pro se litigant constitutes a certificate to the court that:
(a) the person has read the document;
(b) a reasonable attorney in the same circumstances would believe that under the facts his claim or defense may be warranted under the existing law or, if his claim or defense is not warranted under the existing law, a good faith argument exists for the extension, modification, or reversal of existing law;
(c) a reasonable attorney in the same circumstances would believe that his procurement, initiation, continuation, or defense of a civil cause is not intended merely to harass or injure the other party; and
(d) a reasonable attorney in the same circumstances would believe his claim or defense is not frivolous, interposed for delay, or brought for any purpose other than securing proper discovery, joinder of parties, or adjudication of the claim or defense upon which the proceedings are based.
(4) An attorney or pro se litigant participating in a civil or administrative action or defense may be sanctioned for:
(a) filing a frivolous pleading, motion, or document if:
(i) the person has not read the frivolous pleading, motion, or document;
(ii) a reasonable attorney in the same circumstances would believe that under the facts, his claim or defense was clearly not warranted under existing law and that a good faith or reasonable argument did not exist for the extension, modification, or reversal of existing law;
(iii) a reasonable attorney presented with the same circumstances would believe that the procurement, initiation, continuation, or defense of a civil cause was intended merely to harass or injure the other party; or
(iv) a reasonable attorney presented with the same circumstances would believe the pleading, motion, or document is frivolous, interposed for merely delay, or merely brought for any purpose other than securing proper discovery, joinder of parties, or adjudication of the claim or defense upon which the proceedings are based;
(b) making frivolous arguments a reasonable attorney would believe were not reasonably supported by the facts; or
(c) making frivolous arguments that a reasonable attorney would believe were not warranted under the existing law or if there is no good faith argument that exists for the extension, modification, or reversal of existing law.
(B)(1) If a document is not signed or does not otherwise comply with this section, it must be stricken unless it is signed promptly or amended to comply with this section after the omission is called to the attention of the attorney or the party.
(2) If a document is signed in violation of this section, or an attorney or pro se litigant has violated subsection (A)(4), the court, upon its own motion or motion of a party, may impose upon the person in violation any sanction which the court considers just, equitable, and proper under the circumstances.
(C)(1) At the conclusion of a trial and after a verdict for or a verdict against damages has been rendered or a case has been dismissed by a directed verdict, summary judgment, or judgment notwithstanding the verdict, upon motion of the prevailing party, the court shall proceed to determine if the claim or defense was frivolous. An attorney, party, or pro se litigant shall be sanctioned for a frivolous claim or defense if the court finds the attorney, party, or pro se litigant failed to comply with one of the following conditions:
(a) a reasonable attorney in the same circumstances would believe that under the facts, his claim or defense was clearly not warranted under existing law and that a good faith or reasonable argument did not exist for the extension, modification, or reversal of existing law;
(b) a reasonable attorney in the same circumstances would believe that his procurement, initiation, continuation, or defense of the civil suit was intended merely to harass or injure the other party; or
(c) a reasonable attorney in the same circumstances would believe that the case or defense was frivolous as not reasonably founded in fact or was interposed merely for delay, or was merely brought for a purpose other than securing proper discovery, joinder of proposed parties, or adjudication of the claim or defense upon which the proceedings are based.
(2) Unless the court finds by a preponderance of the evidence that an attorney, party, or pro se litigant engaged in advancing a frivolous claim or defense, the attorney, party, or pro se litigant shall not be sanctioned.
(D) A person is entitled to notice and an opportunity to respond before the imposition of sanctions pursuant to the provisions of this section. A court or party proposing a sanction pursuant to this section shall notify the court and all parties of the conduct constituting a violation of the provisions of this section and explain the basis for the potential sanction imposed. Upon notification, the attorney, party, or pro se litigant who allegedly violated subsection (A)(4) has thirty days to respond to the allegations as that person considers appropriate, including, but not limited to, by filing a motion to withdraw the pleading, motion, document, or argument or by offering an explanation of mitigation.
(E) In determining if an attorney, party, or a pro se litigant has violated the provisions of this section, the court shall take into account:
(1) the number of parties;
(2) the complexity of the claims and defenses;
(3) the length of time available to the attorney, party, or pro se litigant to investigate and conduct discovery for alleged violations of the provisions of subsection (A)(4);
(4) information disclosed or undisclosed to the attorney, party, or pro se litigant through discovery and adequate investigation;
(5) previous violations of the provisions of this section;
(6) the response, if any, of the attorney, party, or pro se litigant to the allegation that he violated the provisions of this section; and
(7) other factors the court considers just, equitable, or appropriate under the circumstances.
(F) In determining whether sanctions are appropriate or the severity of a sanction, the court shall consider previous violations of the provisions of this section.
(G) Sanctions may include:
(1) an order for the party represented by an attorney or pro se litigant to pay the reasonable costs and attorney's fees of the prevailing party under a motion pursuant to this section. Costs shall include, but not be limited to, the following: the time required of the prevailing party by the frivolous proceeding, and travel expenses, mileage, parking, costs of reports, and any additional reasonable consequential expenses of the prevailing party resulting from the frivolous proceeding;
(2) an order for the attorney to pay a reasonable fine to the court; or
(3) a directive of a nonmonetary nature, including injunctive relief, designed to deter a future frivolous action or an action in bad faith.
(H) If the court imposes a sanction on an attorney in violation of the provisions of this section, the court shall report its findings to the South Carolina Commission of Lawyer Conduct.
(I) This act shall not alter the South Carolina Rules of Civil Procedure or the South Carolina Appellate Court Rules.
(J) The provisions of this section shall not apply where an attorney or pro se litigant establishes a basis to proceed with litigation, or to assert or controvert an issue therein, that is not frivolous, which includes a good faith argument for an extension, modification, or reversal of the existing law.
(K) The provisions of this section apply in addition to all other remedies available at law or in equity.
(L) The amount requested for damages in a pleading may not be considered in a determination of a violation of the provisions of this section.
(M) All violations of the provisions of this section must be reported to the South Carolina Supreme Court and a public record must be maintained and reported annually to the Governor, Senate, and House of Representatives."
SECTION 6. Chapter 38, Title 15 of the 1976 Code is amended by adding:
"Section 15-38-15. (A)(1) In an action to recover damages resulting from personal injury, wrongful death, or damage to property or to recover damages for economic loss or for noneconomic loss such as mental distress, loss of enjoyment, pain, suffering, loss of reputation, or loss of companionship resulting from tortious conduct, if indivisible damages are determined to be proximately caused by more than one defendant, joint and several liability does not apply to any defendant whose conduct is determined to be less than fifty percent of the total fault for the indivisible damages as compared with the total of: (i) the fault of all the defendants; and (ii) the fault ('comparative negligence'), if any, of plaintiff. A defendant whose conduct is determined to be less than fifty percent of the total fault shall only be liable for that percentage of the indivisible damages determined by the jury or trier of fact.
(B) Apportionment of percentages of fault among defendants is to be determined as specified in subsection (C).
(C) The jury, or the court if there is no jury, shall:
(1) specify the amount of damages;
(2) determine the percentage of fault, if any, of plaintiff and the amount of recoverable damages under applicable rules concerning 'comparative negligence'; and
(3) upon a motion by at least one defendant, where there is a verdict under items (1) and (2) above for damages against two or more defendants for the same indivisible injury, death, or damage to property, specify in a separate verdict under the procedures described at subitem (b) below the percentage of liability that proximately caused the indivisible injury, death, damage to property, or economic loss from tortious conduct, as determined by item (1) above, that is attributable to each defendant whose actions are a proximate cause of the indivisible injury, death, or damage to property. In determining the percentage attributable to each defendant, any fault of the plaintiff, as determined by item (2) above, will be included so that the total of the percentages of fault attributed to the plaintiff and to the defendants must be one hundred percent.
(a) For this purpose, the court may determine that two or more persons are to be treated as a single party. Such treatment must be used where two or more defendants acted in concert or where, by reason of agency, employment, or other legal relationship, a defendant is vicariously responsible for the conduct of another defendant.
(b) After the initial verdict awarding damages is entered and before the special verdict on percentages of liability is rendered, the parties shall be allowed oral argument, with the length of such argument subject to the discretion of the trial judge, on the determination of the percentage attributable to each defendant. However, no additional evidence shall be allowed.
(D) A defendant shall retain the right to assert that another potential tortfeasor, whether or not a party, contributed to the alleged injury or damages and/or may be liable for any or all of the damages alleged by any other party.
(E) Notwithstanding the application of this section, setoff from any settlement received from any potential tortfeasor prior to the verdict shall be applied in proportion to each defendant's percentage of liability as determined pursuant to subsection (C).
(F) This section does not apply to a defendant whose conduct is determined to be wilful, wanton, reckless, grossly negligent, or intentional or conduct involving the use, sale, or possession of alcohol or drugs."
SECTION 7. Section 34-31-20 of the 1976 Code is amended to read:
"Section 34-31-20. (A) In all cases of accounts stated and in all cases wherein any sum or sums of money shall be ascertained and, being due, shall draw interest according to law, the legal interest shall be at the rate of eight and three-fourths percent per annum.
(B) All A money decrees decree and judgments or judgment of courts a court enrolled or entered shall must draw interest according to law. The legal rate of interest is at the rate of twelve percent a year equal to the prime rate as listed in the first edition of the Wall Street Journal published for each calendar year for which the damages are awarded, plus four percentage points, compounded annually. The South Carolina Supreme Court shall issue an order by January 15 of each year confirming the annual prime rate. This section applies to all judgments entered on or after July 1, 2005. For judgments entered between July 1, 2005, and January 14, 2006, the legal rate of interest shall be the first prime rate as published in the first edition of the Wall Street Journal after January 1, 2005, plus four percentage points."
SECTION 8. Section 36-2-803 of the 1976 Code is amended to read:
"Section 36-2-803. (1)(A) A court may exercise personal jurisdiction over a person who acts directly or by an agent as to a cause of action arising from the person's:
(a)(1) transacting any business in this State;
(b)(2) contracting to supply services or things in the State;
(c)(3) commission of a tortious act in whole or in part in this State;
(d)(4) causing tortious injury or death in this State by an act or omission outside this State if he regularly does or solicits business, or engages in any other persistent course of conduct, or derives substantial revenue from goods used or consumed or services rendered, in this State; or
(e)(5) having an interest in, using, or possessing real property in this State; or
(f)(6) contracting to insure any person, property, or risk located within this State at the time of contracting; or
(g)(7) entry into a contract to be performed in whole or in part by either party in this State; or
(h)(8) production, manufacture, or distribution of goods with the reasonable expectation that those goods are to be used or consumed in this State and are so used or consumed.
(2)(B) When jurisdiction over a person is based solely upon this section, only a cause of action arising from acts enumerated in this section may be asserted against him, and such action, if brought in this State, shall not be subject to the provisions of Section 15-7-100 (3)."
SECTION 9. Article 1, Chapter 5, Title 39 of the 1976 Code is amended by adding:
"Section 39-5-39. Notwithstanding another provision of law, it is an unlawful trade practice, pursuant to Section 39-5-20, for an attorney to advertise his services in this State in a false, deceptive, or misleading manner including, but not limited to, the use of a nickname that creates an unreasonable expectation of results."
SECTION 10. The Department of Insurance shall review data reported on annual statements by liability insurers, including, but not limited to, paid claims, reserves, loss adjustment expenses, and such additional data as the department may require by promulgation of bulletin, to determine savings related to a decrease in litigation and claims paid pursuant to litigation after the effective date of this act. The department may require special reports from insurers to determine if savings are realized as a result of the provisions of this act. The department shall compile a report of savings realized and submit it for General Assembly review upon request. Costs or expenses associated with the compilation of this report of savings shall be paid by the insurers pursuant to the provisions of Chapter 13 of Title 38. The Department of Insurance shall review premium and losses by line of insurance to determine if appropriate adjustments have been made based upon the department estimates of savings realized pursuant to the provisions of this act.
SECTION 11. If any provision of SECTION 6 or its application to any person is held invalid, unenforceable, or unconstitutional, this validity, unenforceability, or unconstitutionality shall negate the other provisions or applications of SECTION 6, and to this end, the provisions of SECTION 6 are not severable.
SECTION 12. Sections 15-36-20, 15-36-30, 15-36-40, 15-36-50, and 58-23-90 of the 1976 Code are repealed.
SECTION 13. The provisions of this act do not affect any right, privilege, or provision of the South Carolina Tort Claims Act as contained in Chapter 78, Title 15 of the 1976 Code of South Carolina or the South Carolina Solicitation of Charitable Funds Act as contained in Chapter 56 of Title 33.
SECTION 14. The repeal or amendment by this act of any law, whether temporary or permanent or civil or criminal, does not affect pending actions, rights, duties, or liabilities founded thereon, or alter, discharge, release, or extinguish any penalty, forfeiture, or liability incurred under the repealed or amended law, unless the repealed or amended provision shall so expressly provide. After the effective date of this act, all laws repealed or amended by this act must be taken and treated as remaining in full force and effect for the purpose of sustaining any pending or vested right, civil action, special proceeding, criminal prosecution, or appeal existing as of the effective date of this act, and for the enforcement of rights, duties, penalties, forfeitures, and liabilities as they stood under the repealed or amended laws.
SECTION 15. Except as provided in SECTION 11, if any section, subsection, item, subitem, paragraph, subparagraph, sentence, clause, phrase, or word of this act is for any reason held to be unconstitutional or invalid, such holding shall not affect the constitutionality or validity of the remaining portions of this act, the General Assembly hereby declaring that it would have passed this act, and each and every section, subsection, item, subitem, paragraph, subparagraph, sentence, clause, phrase, and word thereof, irrespective of the fact that any one or more other sections, subsections, items, subitems, paragraphs, subparagraphs, sentences, clauses, phrases, or words hereof may be declared to be unconstitutional, invalid, or otherwise ineffective.
SECTION 16. Upon approval by the Governor:
(1) SECTIONS 1, 7, 10, 11, 13, 14, and 15 take effect;
(2) SECTION 2 takes effect on July 1, 2005, and applies to improvements to real property for which certificates of occupancy are issued by a county or municipality or completion of a final inspection by the responsible local building official after the effective date;
(3) SECTIONS 3, 4, 5, 8, and 12 take effect July 1, 2005 and shall only apply to causes of action arising on or after that date;
(4) SECTION 6 takes effect July 1, 2005, and shall only apply to causes of action arising on or after that date except for causes of actions relating to construction torts which would take effect on July 1, 2005, and apply to improvements to real property that first obtain substantial completion on or after July 1, 2005. For purposes of this section, an improvement to real property obtains substantial completion when a municipality or county issues a certificate of occupancy in the case of new construction, or completes a final inspection in the case of improvements to existing improvements; and
(5) SECTION 9 takes effect but shall only apply to advertisements appearing after that date.
This web page was last updated on Tuesday, June 23, 2009 at 2:16 P.M.